Shyam Telelink Ltd. Vs.
Union of India [2010] INSC 823 (5 October 2010)
Judgment
IN THE SUPREME COURT
OF INDIA CIVIL APPELLATE JURISDICITION CIVIL APPEAL NO.7236 OF 2003 Shyam
Telelink Ltd. now Sistema Shyam Teleservices Ltd. ...Appellant Versus Union of
India ...Respondent
T.S. THAKUR, J.
1.
This
appeal under Section 18(1) of the Telecom Regulatory Authority of India Act,
1997 is directed against an order dated 9th April, 2003 passed by the Telecom
Dispute Settlement and Appellate Tribunal whereby Petition No.24/2001 filed
under Section 14(a)(i) read with Section 14A(1) of the Telecom Regulatory
Authority of India Act, 1997 has been dismissed. The factual matrix giving rise
to the appeal may be summarised at the outset.
2.
The
appellant-Shyam Telelink Ltd. was granted a licence under the Indian Telecom
Act, 1885 on 4th March, 1998 for providing basic telecom services in Rajasthan
Circle. A licence agreement was executed between the parties that, inter alia,
required the appellant to start commercial operations within twelve months from
the date on which the agreement was executed. The appellant's case before the
Tribunal so also before us is that, it was ready to commence commercial
operations in the last week of February 1999 and had sought permission of the
respondents to do so. Permission was, however, denied on the ground that
certain technical deficiencies remained to be removed and certain conditions
for the grant of permission remained to be fulfilled. In the meantime the Union
of India appears to have offered a Migration Package to all the Telecom
Operators in July 1999. Under this package which was offered to the
appellant-Shyam Telelink Ltd. on 22nd July, 1999 the fixed licence fee was to
stand replaced by a revenue-sharing arrangement w.e.f. 1st August, 1999 3
subject to the stipulation that atleast 35% of all outstanding dues including
interest payable as on 31st July, 1999 and liquidated damages in full is paid
by the appellant on or before 15th August, 1999. Migration Package further
provided that the company shall have to accept all the conditions stipulated in
the package and that all proceedings instituted by the licensee or their
associations against the Union of India shall have to be withdrawn.
3.
It
is not in dispute that the appellant gave an unconditional acceptance to the
Migration Package on 22nd July, 1999 nor is it disputed that on 10th August,
1999 the respondent advised the appellant that a sum of Rs.6,74,90,481/- was
payable towards outstanding licence fee and interest due thereon apart from a
sum of Rs.7.30 crores payable towards liquidated damages that were
provisionally determined. The appellant-company was informed that in terms of
the Migration Package at least 35% of the total licence fee along with interest
amounting to Rs.6,74,90,481/- had to be paid by it before 16th August, 4 1999
and the balance dues covered by a Financial Bank Guarantee by the 30th
November, 1999. The liquidated damages payable by the appellant-company were
demanded in full and had to be paid on or before 16th August, 1999.
4.
On
receipt of the intimation demanding payment of the amounts mentioned above the
appellant-company appears to have prayed for waiver of the liquidated damages
on the ground that it could not commence commercial operations by the
stipulated date on account of certain procedural delay. That prayer was upon
consideration turned down with the result that the appellant paid 35% of the
outstanding licence fee and interest amounting to Rs.2.36 crores on 16th
August, 1999. It also paid the full amount of Rs.7.30 crores towards liquidated
damages as demanded by the Government.
5.
Commercial
operations in Rajasthan were finally started by the appellant-company on 5th
June 2000. In March 2001 a demand was raised by the respondent for payment of
a 5 further amount of Rs.70 lakhs as liquidated damages for the delay in the
commissioning of the service. Aggrieved by the demand of Rs.8 crores towards
liquidated damages out of which the appellant had already paid Rs.7.30 crores
on 16th August, 1999 the appellant approached the Tribunal for redress. As
mentioned earlier the appellant's case before the Tribunal was that it was
ready to commence commercial operations in the last week of February 1999 and
had sought permission to do so from the respondent which permission was in an
arbitrary, illegal and discriminatory manner refused by the respondent.
Recovery of the liquidated damages was, therefore bad, argued the appellant who
demanded refund of the entire amount of Rs.8 crores recovered towards
liquidated damages from it.
6.
The
respondent contested the petition before the Tribunal, inter alia, on the
ground that the petitioner- appellant was not entitled to question any demand
arising out of the agreement executed between the parties after it had
unconditionally accepted the Migration Package under 6 which it agreed to deposit
without demur the outstanding licence fee as also the liquidated damages
payable under the licence agreement. The respondent also asserted that the
appellant was not ready with the commissioning of the service as was evident
from the admissions made in several communications sent by it to the
respondent. It was further pointed out by the respondent that the computation
of actual liquidated damages could be undertaken only after the appellant had
commenced commercial operations. The actual charges after such computation were
according to the respondent determined at Rs.29.86 crores but the demand was
restricted to Rs.8 crores in terms of the explicit limitation prescribed under
the licence. An amount of Rs.7.3 crores having already been paid under the
Migration Package, a demand for payment of Rs.70 lakhs only was raised by the
respondent. It was also asserted by the respondent that the appellant had not
disputed calculation of the amount of Rs.7.3 crores as liquidated damages for
non- commissioning of the service at the time of Migration 7 Package and paid
the same with other dues. Having done so, the Migration Package which contained
a specific stipulation that the acceptance of the package "will be deemed
as a full and final settlement of all existing disputes whatsoever irrespective
of whether they are related to the present package or not" could not be
questioned by the petitioner-appellant. The respondent also raised the question
of limitation and assailed the maintainability of the petition on that ground.
By its order dated 9th April, 2003 impugned in this appeal the Tribunal
dismissed the petition filed by the appellant aggrieved whereof the appellant
has filed C.A. No.7236 of 2003 before this Court.
7.
We
have heard learned counsel for the parties and perused the record. A two-fold
contention was urged in support of the appeal by counsel appearing for the
appellant. Firstly, it was contended that the appellant was ready to commence
commercial operations in February 1999 i.e. within one year of the date on
which the agreement was signed between the parties. The fact that the
petitioner had 8 applied for the grant of permission to commence commercial
operations in Jaipur from 3rd February, 1999 was according to the appellant
sufficient to show its readiness to commence such operations. There is, in our
opinion, no force in that contention. It is not disputed that the actual
operations started only on 5th June, 2000. The material placed before the
Tribunal clearly established that during the intervening period the appellant
had been informed by the respondent that clearance for commencing commercial
operations could be considered only after the following requirements of the
licence agreement were complied with:
a. Payment of next
instalment of licence fee due on 3.3.1999;
b. Provision of
Performance Bank Guarantee (PBG) and enhanced Financial Bank Guarantee (FBG)
for requisite amount and validity before commencement of succeeding year on
3.3.1999;
c. Rectification of
deficiencies pointed out by TEC before the commencement of commercial
operations;
d. Submission of plan in
respect of providing Direct Exchange Lines (DEL-s) and Village Public
Telephones (VPT-s) as per committed targets failing which Liquidated Damages
(LD-s) are payable; and (e) Establishment of a separate bank account (an escrow
account as stipulated under condition 18.6 of the Licence Agreement).
8.
Material
further established that the deficiencies pointed out by the TEC could not be
rectified by M/s Qualcomm manufacturer of the equipment purchased by the
appellant forcing the latter to go for a new set of equipment from a new vendor
in December 1999 which equipment was finally delivered and installed in April
2000. It was only after the installation of the said equipment that fresh test
10 certificates were issued by TEC on 1st June, 2000 leading to the start of
the commercial operations on 5th June, 2000. The fact that the appellant was
not ready to commence commercial operations in February 1999 is evident from
its own letter dated 19th July, 1999 in which the appellant had clearly
admitted that the system was not yet ready for such operations and that the
appellant was engaged only in monitoring and testing the credential of the new
technology and the related software/hardware. It is also evident from the
letter of the appellant dated 25th August, 1999 that the appellant was not in a
position to indicate any firm date for a formal launch of the service as the
system was not yet in a position to do so. The relevant part of the letter
reads as under:
"............ at
this stage we are unable to indicate any date for formal commissioning of the
commercial launch of the service since still there are bugs in the system
provided by our supplier. In any case the testing has to continue for
monitoring the behaviour of the equipment even after 75% loading of the system
which is also being followed by DoT/MTNL, while acceptance testing of the 11
systems. However, we hope to commercialize the services by middle of December
1999, as supplier is continuously working to resolve the bugs in the
software."
9.
In
the light of the above admission which is the best evidence against the
appellant, it is not open to the appellant to argue that it was ready to start
commercial operations in February 1999. The Tribunal was, therefore, perfectly
justified in holding that the commercial operations were started only on 5th
June, 2000 and that for the intervening period such operations could not be
commenced on account of deficiencies that were attributed entirely to the
defects in the system which the appellant had installed. The Tribunal was also
justified in our opinion in holding that the denial of permission to the
appellant was neither arbitrary nor mala fide especially when the conditions in
the licence agreement requiring the appellant to arrange and install suitable
equipment to meet the prevailing technical specifications by Telecommunication
Engineering Centre were not complied with nor were all performance tests 12
required for successful commissioning of the services carried out by the
Licensor before the services are commissioned for public use.
10.
The
argument that the respondent has acted arbitrarily and in a discriminatory
manner by overlooking similar deficiencies in the case of other service
providers has also been correctly repelled by the Tribunal on the ground that
the nature of the deficiencies found in the case of the appellant have not been
found similar to those found in other cases where permission was granted. As a
matter of fact, the appellant was given an opportunity to implead the other
service providers so that the allegation could be examined in detail but the
appellant failed to do so nor was any material placed on record to show that
any discriminatory treatment was meted out to it. At any rate so long as the
conditions of the agreement entitled the respondents to decline permission to
commence commercial operations on account of failure on the part of the
appellant to comply with the conditions stipulated in the said 13 agreement,
which condition included a defect-free efficient system, the fact that some
other service providers were given permission in the peculiar facts of their
cases and deficiencies allegedly noticed in their system could not make out a
case for the appellant to question the demand raised on the basis of a package
which the appellant had accepted unconditionally and pursuant to which
acceptance a substantial part of the liquidated damages amounting to Rs.7.3
crores had been deposited by it without any demur.
11.
The
Tribunal has also held and in our view correctly so that the computation of the
liquidated damages for non- commencing of the services as well as limiting the
same to a total amount of Rs.8 crores was in conformity with the licence conditions
executed between the parties. There is nothing before us to suggest that any
error has crept in the computation of liquidated damages nor was any such error
pointed out before the Tribunal. As a matter of fact, according to the
respondents the amount of damages works 14 out to Rs.29.86 crores was limited
to Rs.8 crores in explicit terms of the limitation laid down in the licence
agreement.
12.
The
factual aspects apart we need to remember that the payment of liquidated
damages was an essential condition of the Migration Package which was offered
to the service providers. Unconditional acceptance of the package including the
payment of outstanding licence fee with interest due thereon and liquidated
damages was a specific requirement of the Migration Package which was
unequivocally accepted by the appellant in terms of the declaration made in the
following words:
".. With
reference to the letter No.842- 153/99-VAS (Vol.V) (Pt.) dated 22nd July, 1999
on the subject noted above, I hereby covey unconditional acceptance on behalf
of the Licensee with regard to the package proposed for migration of the
existing licenses to NTP 1999 Regime on the terms and conditions in the letter
under reference....
"
13.
The
unconditional acceptance of the terms of the package and the benefit which the
appellant derived under 15 the same will estop the appellant from challenging
the recovery of the dues under the package or the process of its determination.
No dispute has been raised by the appellant and rightly so in regard to the
payment of outstanding licence fee or the interest due thereon. The controversy
is limited to the computation of liquidated damages of Rs.8 crores out of which
Rs.7.3 crores was paid by the appellant in the beginning without any objection
followed by a payment of Rs.70 lakhs made on 29th May, 2001. Although the
appellant had sought waiver of the liquidated damages yet upon rejection of
that request it had made the payment of the amount demanded which signified a
clear acceptance on its part of the obligation to pay. If the appellant
proposed to continue with its challenge to demand, nothing prevented it from
taking recourse to appropriate proceedings and taking the adjudication process
to its logical conclusion before exercising its option. Far from doing so, the
appellant gave up the plea of waiver and deposited the amount which clearly
indicates acceptance on its part of its liability to pay 16 especially when it
was only upon such payment that it could be permitted to avail of the Migration
Package. Allowing the appellant at this stage to question the demand raised
under the Migration Package would amount to permitting the appellant to accept
what was favourable to it and reject what was not. The appellant cannot
approbate and reprobate. The maxim qui approbat non reprobat (one who
approbates cannot reprobate) is firmly embodied in English Common Law and often
applied by Courts in this country. It is akin to the doctrine of benefits and
burdens which at its most basic level provides that a person taking advantage
under an instrument which both grants a benefit and imposes a burden cannot
take the former without complying with the latter. A person cannot approbate
and reprobate or accept and reject the same instrument. In Ambu Nair v. Kelu
Nair AIR 1933 PC 167 the doctrine was explained thus: "Having thus, almost
in terms, offered to be redeemed under the usufructuary mortgage in order to
get payment of the other 17 mortgage debt, the appellant, Their Lordships
think, cannot now turn round and say that redemption under the usufructuary
mortgage had been barred nearly seventeen years before he so obtained payment.
It is a well- accepted principle that a party cannot both approbate and
reprobate. He cannot, to use the words of Honyman, J. in Smith v. Baker (1878)
LR 8 CP 350 at p. 357 `at the same time blow hot and cold. He cannot say at one
time that the transaction is valid and thereby obtain some advantage to which
he could only be entitled on the footing that it is valid, and at another time
say it is void for the purpose of securing some further advantage'."
14.
View
taken in the above decision has been reiterated by this Court in City
Montessori School v. State of Uttar Pradesh and Ors. (2009) 14 SCC 253. To the
same effect is the decision of this Court in New Bihar Biri Leaves Co. v. State
of Bihar 1981 (1) SCC 537 where this Court said :
"It is a
fundamental principle of general application that if a person of his own
accord, accepts a contract on certain terms and works out the contract, he
cannot be allowed to adhere to and abide by some of the terms of the contract
which proved advantageous to him and repudiate the other terms of the same
contract which might be 18 disadvantageous to him. The maxim is qui approbat
non reprobat (one who approbates cannot reprobate). This principle, though
originally borrowed from Scots Law, is now firmly embodied in English Common
Law. According to it, a party to an instrument or transaction cannot take
advantage of one part of a document or transaction and reject the rest. That is
to say, no party can accept and reject the same instrument or transaction (Per
Scrutton, L.J., Verschures Creameries Ltd. v. Hull & Netherlands Steamship
Co.)"
15.
The
decision of this Court in R.N. Goswain v. Yashpal Dhir AIR 1993 SC 352, brings
in the doctrine of election in support of the very same conclusion in the
following words :
"10. Law does
not permit a person to both approbate and reprobate. This principle is based on
the doctrine of election which postulates that no party can accept and reject
the same instrument and that "a person cannot say at one time that a
transaction is valid and thereby obtain some advantage, to which he could only
be entitled on the footing that it is valid, and then turn round and say it is
void for the purpose of securing some other advantage". [See: Verschures
Creameries Ltd. v. Hull and Netherlands Steamship Co. Ltd. (1921) 2 KB 608, at
p.612, Scrutton, L.J.] According to Halsbury's Laws of England, 4th Edn., Vol.
16, "after taking an advantage under an order (for example for the payment
of costs) a party may be precluded from saying that it 19 is invalid and
asking to set it aside". (para 1508)"
16.
In
America Estoppel by acceptance of benefits is one of the recognized situations
that would prevent a party from taking up inconsistent positions qua a contract
or transaction under which it has benefited.
17.
American
Jurisprudence, 2nd Edition, Volume 28, pages 677-680 discusses `Estoppel by
acceptance of benefits' in the following passage:
"Estoppel by the
acceptance of benefits: Estoppel is frequently based upon the acceptance and
retention, by one having knowledge or notice of the facts, of benefits from a
transaction, contract, instrument, regulation which he might have rejected or
contested. This doctrine is obviously a branch of the rule against assuming
inconsistent positions.
As a general
principle, one who knowingly accepts the benefits of a contract or conveyance
is estopped to deny the validity or binding effect on him of such contract or
conveyance.
This rule has to be
applied to do equity and must not be applied in such a manner as to 20 violate
the principles of right and good conscience."
18.
For
the reasons set out by us hereinabove, we have no hesitation in holding that
the appellant was not entitled to question the terms of the Migration Package
after unconditionally accepting and acting upon the same.
19.
In
the result this appeal fails and is hereby dismissed but in the circumstances
without any order as to costs.
.................................J.
(MARKANDEY KATJU)
.................................J.
Back