Vs. State of Kerala & Anr  Insc 884 (30 November 2006)
Lakshmanan & Altamas Kabir Altamas Kabir,J.
appellant entered into an agreement with the State of Kerala on 10th October, 1985 whereunder he
was entrusted with the construction work of the Chavara Distributory from
Ch.7440M to 9440M and 10475M to 14767M. Disputes having arisen between the
parties, the matter was referred to arbitration. The Superintending Engineer, Siruvani
Project, Palghat, .the designated Arbitrator in terms of the contract, was
appointed as the sole Arbitrator.
award, which was published on 2nd September, 1989, the Arbitrator awarded a total sum of Rs. 42,21,000/- with 12%
interest per annum from the date of the award. Upon the passing of the award
the appellant herein filed O.P. (Arb.) 40/89 in the court below under Section
17 of the Arbitration Act for passing a decree in terms of the award. The State
of Kerala filed a petition under Section 30
of the Act challenging the award and for setting aside the same.
application filed by the State was dismissed and aggrieved thereby the State of
Kerala preferred an appeal in the High Court of Kerala at Ernakulam, being MFA
No. 980 of 1990 C.
appellant herein raised claims under 12 different heads but the Arbitrator
allowed only claims (a), (e), (g), (i) and (k). Although, in the memorandum of
appeal, the entire award in favour of the appellant had been challenged, but
the arguments were addressed only with regard to claims under heads (a), (g), (i)
and (k). A preliminary objection was raised in the appeal that the
Superintending Engineer, who had been appointed as the Arbitrator and had
entered on the reference, had been suspended from service for gross
mal-practice, and the Government had informed all concerned that the Arbitrator
was not to continue with the reference. The Arbitrator retired on
superannuation while he was under suspension and the award was made after his
to the State of Kerala, in the circumstances, the award
passed by the Arbitrator was without jurisdiction.
aforesaid objection being preliminary in nature, the same was taken up first
for consideration and it was held by the High Court that such an objection was
without any merit.
Arbitrator, who was working as Superintending Engineer was placed under
suspension on 31st May,
1989. As per an
agreement between the parties on 14th February, 1989, the time for making and publishing the award was extended upto
14th June, 1989. Even after the Arbitrator was
suspended from service, both sides had agreed on 14th June, 1989 to extend the
time further for making and publishing the award upto 14th October, 1989. The
Arbitrator retired from service while under suspension on 30th June, 1989. In the light of the said facts,
the High Court agreed that the court below could not revoke the authority of
the Arbitrator, which could only be done under Section 5 of the Arbitration
Act, with the leave of the Court. Accordingly, the preliminary objection raised
on behalf of the State of Kerala that
the Arbitrator had no authority to continue with the arbitration after his
suspension or retirement, was rejected by the High Court.
(a) of the appellant herein involved the claimant's entitlement to get
compensation for interruption of work by anti-social elements and failure of
the Department in removing such miscreants from the sites which caused the
claimant heavy financial losses by way of idle men and machinery, plant and
equipment. The claim made under the aforesaid head was for a sum of Rs.11,40,000/-.
The Arbitrator was satisfied that there was interruption of work by anti-social
elements and that the State had failed to remove such obstruction from the
site. Accordingly, the Arbitrator awarded a sum of Rs. 7,30,000/- under this
(g) was confined to the question as to whether the claimant was entitled to
compensation for the losses suffered by him on account of price escalation of
materials that had taken place during the extended period of completion when
such extension of time was necessitated by departmental failure, although there
was no provision for escalation of costs in the contract. Under the said clause
the appellant claimed an amount of Rs.39,90,198/- but was awarded a sum of
Rs.11,70,000/- over and above the amount as per the rates in the agreement for
the work done after the original period of contract till 9th February, 1987.
(i) was confined to the question regarding the claimant's entitlement for
compensation for the losses purported to have been suffered by him because the
Department was unable to hand over a suitable quarry which resulted in the
claimant having to bring rubble and metal from far off places involving
additional transportation costs.
Arbitrator came to a positive finding that the claimant had procured rubble
from quarries situated at different places.
to the initial estimate, the quarry ought to have been within 25 Kms. from the
place of work, but from the evidence it would be clear that the nearest quarry
from which the claimant had to procure rubble would be about 47 Km. away from
the site of the work. The other quarries were even further away from the work
site. It was the definite finding of the Arbitrator that the average extra lead
involved would be not less than 22 Kms. and accordingly while the claimant had
claimed a sum of Rs.24,86,574/-, the Arbitrator awarded a sum of Rs.13,35,000/-
under this head for the work executed up to 9th February, 1987.
other claim which was pressed by the appellant was claim (k) relating to losses
suffered by him on account of non-availability of a suitable dumping yard for
dumping excess earth. While a claim for a sum of Rs.13,72,554/- was made in
this regard, the Arbitrator awarded a sum of Rs.6,62,000/- under this head.
agreement relating to the handing over of the site to the claimant was executed
on 10th October, 1985 and on 25th October, 1985, the respondents instructed the claimant to start the work
and to complete the same within the agreement period of eleven months. However,
while the period of completion of eleven months for the whole work was to
expire on 24th
September, 1986, the
same could not be completed on the scheduled dates and under clause 50 of the
General Conditions of Contract extension of time was sought by the appellant
for completing the work. Clause 50 of the General Conditions of Contract
provides that if failure to complete the work was the result of delays on the
part of Government in supplying materials or equipment it had undertaken to
supply under the contract or from delays in handing over sites or from increase
in the quantity of the work to be done under the contract or force majeure, an
appropriate extension of time would be given. Finding that the said clause was
operative, the respondents extended the time of completion but while doing so
made it conditional that such extension of time would be subject to execution
of a Supplemental Agreement to the effect that the contractor would not be
eligible for any enhanced rate for the work done during the extended period.
According to the appellant, he had no option but to sign the agreement, though
under protest, since he had undertaken to complete the work.
appellant appears to have moved to the site and commenced the work on 1st November, 1985 but he was not allowed to proceed
with the work because of external interference involving law and order problems
created by local miscreants and anti-social elements under cover of union
activities. Although, initially such a claim was denied on behalf of the
respondents and the law and order situation was said to be only a labour
dispute between the claimant and his workers, ultimately from the evidence the
Arbitrator came to the finding that the issue was one of law and order which could
only have been controlled by the Governmental agencies.
Arbitrator also came to a finding that in order to maintain peace at the work
site, the claimant had to keep the entire local work force in the muster rolls
and to pay wages when the actual work was done with bull dozers. The Arbitrator
was satisfied that although the claimant had aimed to complete the work within
the original period, he was faced with adverse site conditions which are not
usually met with at construction sites.
Arbitrator was also satisfied with the claimant's contention that adequate
space had not been provided for dumping the excess earth which had to be
conveyed to distant places for dumping. On assessment of the evidence and the
ground realities under which the claimant was constrained to execute the
Supplemental Agreement, the Arbitrator was convinced that the claim made by the
claimant under the different heads could not be brushed aside.
from the preliminary objection taken with regard to the competence of the
Arbitrator to complete the arbitration proceedings and to publish his award, it
was also contended before the Arbitrator that the State had no responsibility
in settling the disputes between the claimant and his employees and it was
really due to the non-cooperation of the claimant that a settlement could not
be arrived at with the workers. It was contended that under such circumstances
claim (a) could not be granted.
also contended that there was no provision in the Agreement by which the Department
could be made liable to compensate any loss sustained by the contractor because
of intervention of third parties. It was contended that it is one thing to say
that the State is responsible for maintaining law and order and on the other
hand to make the State liable under the terms of the Agreement to compensate
the contractor for losses allegedly suffered during the period of disturbance.
consideration of the case made out on behalf of the respective parties, the
Arbitrator made his award in respect of each of the several heads of claims on
the losses actually suffered by the appellant while trying to carry out and
complete the tender work. The Arbitrator filed his award before the Subordinate
Judge, Kottarakkara, on which a decree was passed in terms of the award but
modifying the appellant's claim for interest. The respondents preferred an
appeal to the High Court of Kerala at Ernakulam.
stand taken before the Arbitrator was reiterated by the parties before the High
Court of Kerala at Ernakulam in the said appeal. In addition, arguments were
addressed on the scope of interference by the High Court in an award passed by
the Arbitrator, which award was a speaking award.
looking into the Agreement, the High Court was of the view that the Arbitrator
had exceeded his jurisdiction in granting claim (a). The High Court felt that
the Arbitrator had travelled outside the Agreement and had acted without
jurisdiction in granting such claim.
in respect of claim (g), the High Court took note of the fact that by virtue of
the Supplemental Agreement which had to be executed for extension of the
original period of completion of the work, the appellant herein was not
entitled to enhanced rates during the extended period. In respect of claim (g)
also, the High Court found that the Arbitrator had travelled outside the terms
of the contract and had mis- conducted himself.
the original Agreement did not contain a clause for escalation of rates. On the
other hand, the Supplemental Agreement contained a specific provision that the
contractor would carry out all further works within the extended period at the
rates and in the manner agreed to in the Agreement and would not claim any
enhanced rate for such item of work on account of the extension of time either
due to the increase in the rate of labour or materials or on any other ground
whatsoever. The High Court took the view that although the Arbitrator had come
to a finding that the appellant had to execute the Supplemental Agreement under
the force of circumstances, there was no material before the Arbitrator in
support of such contention. On such finding also, the High Court held that the
Arbitrator had acted beyond his jurisdiction in allowing claim (g).
award of the Arbitrator against claim (i) also met the same fate and the High
Court held that the Arbitrator had travelled outside the contract in granting
such claim and thus mis-conducted himself.
only claim which was allowed by the High Court was claim (k).
High Court accordingly set aside the judgment and decree of the court below to
the extent it affirmed the award as far as claims (a), (g) and (i) are
said order of the High Court is the subject-matter of the present appeal.
for the appellant, Mr.Dushyant Dave, learned senior advocate, urged that the
High Court while reversing the award under claims (a), (g) and (i) had failed
to take into consideration the finding of the Arbitrator that the appellant had
suffered heavy losses on account of the law and order problem which had been
created at the work site and that he had been compelled to complete the work
was made to the letter dated 7th September, 1985 addressed by the appellant to
the Superintending Engineer, K.I.P.(RB) Circle, Kottarakkara, regarding
extension of time to complete the work under tender with the hope that the
Department would reciprocate his gesture and consider the special circumstances
under which he had given his consent for extension of the period for completion
of the work.
was also made to another letter dated 24th September, 1986 written by the appellant to the
said Superintending Engineer informing him of the problems that were being
faced for completion of the work and requesting that his accounts be settled
and that he be freed from the entanglements.
last letter referred to by Mr. Dave was written by the appellant to the said
Superintending Engineer on 30th September, 1986 indicating that he was carrying out the work despite all the difficulties
although the same was not a solution to the genuine problems being faced by him
as indicated in the earlier letters.
urged that having regard to the ground realities, it was within the powers of
the Court to grant relief on account of escalation of costs in interrupted
projects, although there may not be any specific provision for such escalation
in the contract itself.
support of his submissions, Mr. Dave firstly referred to the decision of this
Court in P.M. Paul vs. Union of India, 1989 Supp.(1) SCC 368, wherein a dispute
arose regarding payment of escalated costs. By an order of this Court, the
dispute between the parties was referred to a retired Judge of this Court to
ascertain who was responsible for the delay in completion of the building, what
was the repercussions of the delay and how the consequences were to be
apportioned. It had been contended therein that in the absence of any
escalation clause it was not permissible for the Arbitrator to grant any
escalation price sought by the contractor. The Arbitrator, however, noted that
the claim related to the losses caused due to increase in prices of materials
and costs of labour and transport during the extended period of the contract
and accordingly allowed 20 per cent of the compensation sought. The question
before this Court was whether the Arbitrator had travelled beyond his
jurisdiction in awarding escalation costs and charges. This Court came to a
finding that the Arbitrator had not mis-conducted himself in awarding the
amount as he had done. Once it was found that there was delay in execution of
the contract due to the conduct of the respondent, respondent was liable for
the consequences of the delay, namely, increase in prices. It was held that the
claim was not outside the purview of the contract and arose as an incidence of
the contract and the Arbitrator had jurisdiction to make such award.
was then made to the decision of this Court in T.P. George vs. State of Kerala And Anr., (2001) 2 SCC 758, where a similar
situation arose and the contractor was compelled to execute a Supplemental
Agreement. Although, a question was raised as to whether the Supplemental
Agreement debarred the contractor from pursuing his claims, the Arbitrator
allowed the claims which were however set aside by the High Court. This Court
in appeal held that the High Court had erred in setting aside the award
regarding those claims notwithstanding the fact that the Supplemental Agreement
had been executed between the appellant and the State Government. The grant of
interest by the Arbitrator, which had been disallowed by the High Court, was
also allowed by this Court.
Dave contended that even in the absence of any escalation clause, if it is
found that the escalation of costs had been occasioned by circumstances which
were not anticipated at the initial stage and was attributable to the
respondents, there was no reason why the Arbitrator could not take notice of
the ground reality and to award escalation costs. It was urged that had the
respondents provided for the rubble to be obtained for the work from the quarry
at Mannady, the appellant would not have had to bear the extra transportation
charges for bringing such rubble from far away quarries. The same applied to
providing a suitable place for dumping of excess earth and the failure of the
respondents to maintain the law and order problem that had been created at the
submissions advanced on behalf of the appellant were strongly opposed on behalf
of the State Government with particular reference to the award in respect of
claims (a) and (g) since the Original Agreement did not provide for such
escalation and the Supplemental Agreement which had been executed clearly
stipulated that no extra rates would be allowed. It was contended that the
Department had never failed to perform its contractual obligations, and, in any
event, the delay in completing the work was not on account of any neglect on
the part of the State but on account of labour trouble involving the appellant
and his workmen at the site.
Muth Raj, who appeared for the State, contended that as had been observed by
this Court as far back as in 1960 in M/s. Alopi Parshad & Sons Limited vs.
The Union of India, reported in (1960) 2 SCR 793, provision for payment of charges
at rates specified had been made in the contract and the arbitrators could not
ignore the express covenants between the parties and award amounts not agreed
to be paid. It was observed further that a contract is not frustrated merely
because the circumstances in which it is made is altered and that the Courts
have no general power to absolve a party from the performance of his part of
the contract merely because its performance has become onerous on account of an
unforeseen turn of events. According to Mr. Muth Raj the award made in the
instant case could not also be justified on the basis of quantum meruit since
such a concept would be applicable when services are rendered but the price
thereof is not fixed by a contract.
Raj also referred to various other decisions of this Court, including the
decision in State of U.P. vs. Patel Engg. Co. Ltd. And Ors.,
reported in (2004) 10 SCC 566, where a question arose as to whether on the
basis of a modified contract which specifically excluded payment of freight
charges, claims for variation in payment of such charges could be awarded by
the arbitrator. It was held that the arbitrators had exceeded their
jurisdiction in awarding freight charges in respect of steel and handling
transportation charges and that the District Judge had rightly held that the
same was not sustainable inasmuch as the claimant was not entitled to such
freight charges. It was urged that when no provision had been made in the
contract for escalation of costs and the Supplemental Agreement entered into
between the parties specifically provided that the contractor would not claim
any enhanced rate for the work performed during the extended period of the
contract, the Arbitrator had wrongly allowed some of the claims made by the appellant
on account of escalation of costs and the High Court had rightly disallowed the
question which we are called upon to answer in the instant appeal is whether in
the absence of any price escalation clause in the Original Agreement and a specific
prohibition to the contrary in the Supplemental Agreement, the appellant could
have made any claim on account of escalation of costs and whether the
Arbitrator exceeded his jurisdiction in allowing such claims as had been found
by the High Court.
the parties would be bound by the terms agreed upon in the contract, but in the
event one of the parties to the contract is unable to fulfil its obligations
under the contract which has a direct bearing on the work to be executed by the
other party, the Arbitrator is vested with the authority to compensate the
second party for the extra costs incurred by him as a result of the failure of
the first party to live up to its obligations. That is the distinguishing
feature of cases of this nature and M/s. Alopi Parshad's case (supra) and also
Patel Engg.'s case (supra). As was pointed out by Mr. Dave, the said principle
was recognized by this Court in P.M. Paul's (supra) , where a reference was
made to a retired Judge of this Court to fix responsibility for the delay in
construction of the building and the repercussions of such delay. Based on the
findings of the learned Judge, this Court gave its approval to the excess
amount awarded by the arbitrator on account of increase in price of materials
and costs of labour and transport during the extended period of the contract,
even in the absence of any escalation clause.
said principle was reiterated by this Court in T.P. George's case (supra).
have intentionally set out the background in which the Arbitrator made his
award in order to examine the genuineness and/or validity of the appellant's
claim under those heads which had been allowed by the Arbitrator. It is quite
apparent that the appellant was prevented by unforeseen circumstances from
completing the work within the stipulated period of eleven months and that such
delay could have been prevented had the State Government stepped in to maintain
the law and order problem which had been created at the work site. It is also
clear that the rubble and metal, which should have been available at the
departmental quarry at Mannady, had to be obtained from quarries which were
situated at double the distance, and even more, resulting in doubling of the
transportation charges. Even the space for dumping of excess earth was not
provided by the respondents which compelled the appellant to dump the excess
earth at a place which was far away from the work site entailing extra costs
for the same.
aforesaid circumstances, the Arbitrator appears to have acted within his
jurisdiction in allowing some of the claims on account of escalation of costs
which was referable to the execution of the work during the extended period. In
our judgment, the view taken by the High Court was on a rigid interpretation of
the terms of contract and the Supplemental Agreement executed between the
parties, which was not warranted by the turn of events.
accordingly allow the appeal and set aside the order passed by the High Court
and restore the award made by the Arbitrator.
will, however, be no order as to costs.
Pages: 1 2