Pune
Cantonment Board & Anr Vs. M.P.J. Builders & Anr [1996] INSC 930 (9 August 1996)
Verma,
Jagdish Saran (J) Verma, Jagdish Saran (J) Venkataswami K. (J) J.S. Verma, J.
CITATION:
JT 1996 (7) 123 1996 SCALE (5)713
ACT:
HEAD NOTE:
The
dispute relates to the building sanction of House No.2, Sholapur Bazar Road, Pune,
which falls within the area of Pune Cantonment governed by the Cantonments Act,
1924 (hereinafter referred to as 'the act) The respondent no.1 was granted a
building sanction under Section 181 of the Act on 2.7.1981 effective from
6.7.1981. The building was intended to be used for commercial residential
purposes, it was to be an RCC framed structure and to consist of ground and
five upper stories (i.e. Stilt + six upper stories); the nature of soil was
'hard rock'; the construction work was to be commenced within one year of the
sanction i.e. before 6.7.1982; and was to be completed within 12 months from
the date of commencement of the work. The building bye-laws existing at the
time of the sanction did not contain any restrictions with regard to the Floor
Area Ratio (FAR) or number of floors or height of the building. By a letter
dated 3.7.1982, barely three days before expiry of the permissible period for
commencement of the work, a letter was sent by the respondent No. 1 stating
that the work had been commenced on that day. For the purposes of this case,
the appellants did not dispute this claim of the respondent no.1. According to
the conditions of the building sanction imposed under the relevant statutory
provisions, the construction of the building had to be completed within 12
calendar months from the date of commencement of the work i.e. upto 3.7.1983.
Admittedly, the construction of the building was neither completed nor was
extension of time sought within that period. The respondent No. 1 claims to
have made an application for extension of time to complete the construction on
24.9.1983, after expiry of the time allowed. For the purposes of this case the
appellants do not dispute even this claim. The contents of that application
alleged to have been made by the respondent no.1, are as under :
"MRJ:
9/86/736 24.9.1983 The Executive Officers, Cantonment Board, Pune Sub:
Extension of time.
Ref:
Your sanction No. 2/SH/B3 dated 6.7.81, for our project at No. 2, Sholapur Bazar
road.
Sir, We
have commenced the above work with effect from 3.7.82 and your office was
intimated accordingly vide our letter No. MPJ:MK/7/82, dated 3.7.1982.
It was
not possible to complete the works within a span of one year due to the various
following reasons:
1.Hard
rock is met with for basement foundation which requires chiselling.
2.Non-availability
of building materials.
3.Due
to change in the strata now met with, structural detailing requires some
changes.
4.Due
to various other difficulties.
We,
therefore, request you to kindly grant us an extension of time for a further
period of 24 months and oblige.
Yours
faithfully, for MPJ Builders.
Sd/- (Ramesh
Kumar More) Partner." On 24.5.1984, an engineer of the Cantonment Board
inspected the site and submitted a report that no erection work of the building
had been commenced till then; the owner had not made any application for
extension of time and the sanction had lapsed. The making of this report is
undisputed. Thereafter, on 9.9.1985, an application, said to be the second
application for extension of time was made by the respondent no.1. That
application is as under :
"BY
REGISTERED A.D HPJ\RRH\9\85\106 Sept. 9th 1985 Executive Officer, Pune Cantonment Boards PUNE 411 OO1 Ref.
:
(a)
Your sanction No.2/SH/B- 3 of 6/7/1981 for
our project at No.2 Sholapur Bazar road.
(b)Our
letter No . HPJ/MK/7/82/343 of 3.7.1982 regarding intimation of commencement.
(c)Our
letter No.MPJ/9/83/736 of Sir, Due to various unforeseen reasons and
difficulties, we could make substantial progress with the work at our site at 2 Sholapur Bazar Road.
We
request you to grant us further extension of 18 months and oblige.
We
assure you that we will try our best to complete the building within this
extended period.
Thanking
you, For MPJ Builders, (Ramesh Kumar More) Partner." On that application,
a report dated 3.10.1985 was submitted by an Officer of the Cantonment Board.
Relevant part of that report is as under :
"The
party has not started the construction from the date of sanction and not taken
any extension of time limit for completion of work from this office.
On
site inspection, it is found that the owner of this property had started
excavation work. Which work is in progress.
Submitted
to your order's pl. Sd/- 3.10.85" The Cantonment Executive Officer,
exercising the power of the Board, granted extension of time for a period of
one year from the date of that order dated 2.5.1986 as under:
"02
May 1986 From The Cantonment Executive Officer, Poona Cantonment Boards Poona.
To Shri
Ramesh Kumar More, Partner, C/o MPJ Builders, Poona Bottling Co.Ltd., 4101/1,
Bombay Poona Road, Dapodi, PUNE 411 012.
Subject
: Grant of Extension of time for completion of work H.No.2, sholapur Bazar, Pune Cantt.
Reference
: Your application dt.09.9.1985 Dear Sir, Extension of time for completion of
work for a period of one year is hereby granted.
Yours
faithfully, Sd/- CANTT. EXECUTIVE OFFICER." Prior to the grant of
extension of time by the Cantonment Executive Officer on 2.5.1986 or even the
8application for extension of time dated 9.9.1985, certain changes had been
made in the building bye-laws imposing additional restrictions. All subsequent
building sanctions had to be granted thereafter subject to these additional
restrictions also. The first set of restrictions were imposed on 24.12.1982
under which the maximum number of stories which could be constructed were
reduced to the ground floor + two upper stories i.e. in all three stories
including the ground floor. The maximum permissible FAR commonly known as FAR
was two and the maximum permissible built up area became 1/3rd. These
restrictions were imposed under Section 181(2) of the Act which later became
Section 181-A, in the public interest to regulate the building activities in
the cantonment area. More restrictions were imposed on 26.3.1984 under which
the permissible FAR was reduced from two to one. It is to be remembered that
the report dated 24.5.1984 of the Cantonment Engineer clearly mentioned the
admitted fact that no erection work had been commenced by the respondents till
then. The question of extension of time to make the construction according to
the initially sanctioned plan had to be decided in this background taking into
account the fact that no erection of the building had commenced till both sets
of further restrictions had been imposed; and according to the additional
restrictions, the kind of building construction sanctioned on 2.7.1981 could
not be permitted, if the question of sanction was to be considered afresh.
The
GOC-in-Chief in exercise of his powers under Section 52(1)(b) of the Act
suspended the CEO's order dated 2.5.1986 by an order dated 2.1.1987 and issued
a show cause notice to the Cantonment Board as well as the respondent no.1 to
show cause why the suspension order be not made absolute. After hearing the
parties, the GOC-in-Chief, by order dated 14.2.1987 under Section 52(2)(c) made
the suspension order absolute. It appears that a portion of the building had
been constructed by then and therefore, on 14.3.1987 the GOC-in-Chief made the
consequential order for its demolition.
A writ
petition was then filed on 27.3.1987 in the Bombay High Court by the
respondents which has been allowed and the orders made by the GOC-in-Chief
dated 14.2.1987 and 14.3.1987 have been set aside. The High Court granted some
further time to complete construction of the building according to the
initially sanctioned plan. Aggrieved by the High Court's order, the Pune
Cantonment Board and the GOC- in-Chief have preferred this appeal by special
leave.
It was
common ground before us that the stage of construction till now is : the
basement, a ground floor and the first floor have been constructed; the ground
floor is of an extra height so as to accommodate mezzanine although the
mezzanine floor has not yet been cast; the mezzanine floor sanctioned does not
extend to the entire ground floor area but only to a small portion thereof and
the rest of the ground floor has been left with the extra height. The
construction made so far is already in excess of the permitted FAR of one,
being approximately 1.59. The learned Solicitor General, appearing for the
appellants, on instructions, stated that the appellants are prepared to permit
the respondent no 1 to retain the existing structure and complete the finishing
of the existing structure with the mezzanine according to the initially
sanctioned Plan subject to the condition that no additional slab would be laid
anywhere else. This offer made on behalf of the appellants at the hearing before
us is mentioned since to this extent the appellants consent to grant of relief
to the respondents even if the appeal is allowed.
Mention
may also be made of another relevant fact. The High Court in the impugned
judgment invoked the doctrine of estoppel on the ground that the builders had
acted upon the order of extension and had completed a portion of the building. Shri
F.S.Nariman, learned senior counsel for the respondents, frankly conceded that
he could not support the High Court's order on that ground. We need not,
therefore, consider the applicability of the doctrine of estoppel which is a
clearly untenable plea in the present case.
At
this stages before we proceed to consider the rival contentions, we may notice
the relevant statutory provisions:
"THE
CANTONMENTS ACT, 1924
52
Power of Officer Commanding-in- Chief, the Command, on reference under Sec 51
or otherwise - (1) The Officer Commanding-in-chief, the Command, may at any
time- (a) xxx xxx xxx (b)direct the suspension, for such period as may be
stated in the order of action on any decision of a Board, other than a decision
which has been referred to him under sub-section (1) of Sec. 51, and thereafter
cancel the suspension or after giving the Board a reasonable opportunity of
showing cause why such direction should not be made, direct that the decision
shall not be carried into effect, or that it shall be carried into effect with
such modifications as he may specify.
xxx xxx
xxx 180-A. Powers of Board under certain sections exercisable by Executive
Officer.- The powers, duties and functions of the Board under Sec. 181,
sub-section (1) of Sec. 182, Sec. 183Sec. 183-A and Sec. 185 (excluding the
proviso to sub-section (1) and the proviso to sub-section (2) of the saidSec.
185 shall be exercised or discharged in a civil area by the Executive Officer)
181. Power refuse –
(1)
The Board may either refuse to sanction the erection or re-erection, as the
case may be, of the building, or may sanction it either absolutely or subject
to such directions as it thinks fit to make in writing in respect of all or any
of the following matters, namely :
xxx xxx
xxx and the person erecting or re- erecting the building shall obey all such
written directions in every particular.
(2)
The Board may refuse to sanction the erection or re- erection of any building
on any grounds sufficient in the opinion of the Board affecting the particular
building Provided that the Board shall refuse to accord sanction the erection
or re-erection of any building if such erection or re- erection is not in
conformity with any general scheme sanctioned under Sec.181-A.
xxx xxx
xxx (5) If the Board decides to refuse- to sanction the erection or re-
erection of the building, it shall communicate in writing the reasons for such
refusal to the person by whom notice was given.
xxx xxx
xxx 181-4. Power to sanction general scheme for prevention of over- crowding,
etc. - The Officer Commanding-in-Chief the Command may sanction a general
scheme for erection or re-erection of buildings within such limits as may be
specified in the sanction for the prevention of over crowding or for purpose of
sanitation, or in the interest of persons residing within those limits or for
any other purpose, and may, in pursuance of such scheme, impose restrictions on
the erection or re- erection of buildings within those limits :
Provided
that no such scheme shall be sanctioned by the officer commanding-in-chief, the
command, unless an opportunity has been given by a public notice to be
published locally by the Executive Officer requiring persons affected or likely
to be affected by the proposed scheme, to file their objections or suggestions
in the manner specified in the notice, within a period of fifteen days of the
publication of such notice, and after considering such objections and
suggestions, if any, received by the Executive Officer within the said period.
xxx xxx
xxx 183. Lapse of sanction - Every sanction for the erection or re- erection of
a building given or deemed to have been given by the Board as herein-before provided
shall be available for one year from the date on which it is given, and, if the
building so sanctioned is not begun by the person who has obtained the sanction
or some one lawfully claiming under him within that period, it shall not
thereafter be begun unless the Board on application made therefore, has allowedan
extension of that period.
183-A.
Period for completion of building -A Board when sanctioning the erection or
re-erection, of a building as herein-before provided shall specify a reasonable
period after the work has commenced within which the erection or re-erection is
to be completed, and, if the erection or re-erection is not completed within
the period so fixed, it shall not be continued thereafter without fresh
sanction obtained in the manner herein- before provided, unless the Board on
application made therefor has allowed an extension of that period :
Provided
that not more than two such extensions shall be allowed by the Board in any
case." The learned Solicitor General appearing on behalf of the appellants
advanced several arguments. He submitted that no reasons were given by the
Cantonment Executive Officer for extension of time, on these facts, to justify
grant of the extension. The relevant facts for this purpose were that the sanction
had expired on 3.7.1983 even prior to the making of the alleged first
application for extension of time dated 24.9.1983, assuming that the
application was made, no construction of the building had been commenced within
the time ailowed or even till 3.10.1985 as evident from the inspection note of
that date and much before that date additional restrictions had been imposed on
26.12.1982 and 26.3.1984 by amendments made in the building bye-laws which did
not Permit such a construction. It was contended that these changed
circumstances were of great significance but they were not considered by the
CEO and no reason was given for the extension of time granted by the CEO on
2.5.1986. The learned Solicitor General also submitted that the only ground
mentioned in the application dated 9.9.1985 made by the respondent no.1 did not
justify grant of extension of time to make any construction in breach of the
restrictions imposed meanwhile in 1982 and 1984 when no construction of the
building had been commenced even till 3.10.1985 and the sanction had already
lapsed on 3.7.1983.
It was
urged that the exercise of power by the GOC-in-Chief under Section 52 to set
aside the order made by the CEO was valid for the reasons given by him. We have
already mentioned the offer made by the appellants to permit retention of the
existing structure even if the appeal succeeds.
In
reply, Shri F.S.Nariman, learned senior counsel for the respondents, submitted
that the reasons given in the order of the GOC-in-Chief setting aside the order
of the CEO are in applicable because the additional building restrictions
imposed in 1982 and 1984 did not apply to a building sanction granted prior to
the imposition of those additional restrictions. Shri Nariman heavily relied on
a foot-note dated 4.4.1984 clarifying this position at the end of the relevant
public notice quoted in the decision in Usman Gani J.Khatri &. Ors. etc.
vs. Cantonment Board & Ors., 1992 (3) SCC 455 at 464 as under :
"Note
- It is clarified for information of the general public that the above orders
will be effective from the date the GOC-in- Chief, HQSC, has signed the above
order i.e.March 26, 1984. These restrictions will apply only to the buildings
whose plans will be considered/ passed on or after March 26, 1984. Building plans passed prior to March 26,1984 will be governed by the FSI existing during that period.
Dated April 4, 1984.
Sd/-
S.P. Nijhawan Cantonment Executive Officer, Pune" It is not necsssary to
quote in extenso the public notices imposing the additional restrictions on
24.12.1982 and 26.3.1984, which have been summarised earlier and are not
disputed. The other submission of Shri Nariman was that even though the delay
in making the application for extension of time after expiry of the period of
sanction and imposition of additional restrictions are relevant circumstances
to be considered for granting extension of time yet its non- consideration is
not a jurisdictional defect to denude the CEO of the power to grant extension
of time, Shri Nariman submitted that the initial- building sanction granted to
the respondent no.1 being prior to the imposition of the additional
restrictions which were prospective in operation the further extension of time
to complete the earlier sanctioned building would be governed only by the
building bye-laws existing at the time of grant of the initial sanction. Shri Nariman,
therefore, argued for dismissal of the appeal for these reasons.
Section
180-A empowers the Executive Officer to exercise certain powers, duties and
functions of the Board which include the Board's power to sanction or to refuse
to sanction the erection or re-erection of the building under Section 181, and
to allow the extension of the period for completion of the building. Extension
of time granted by the CEO in the present case was in exercise of this power.
The only question in the present case pertains to the validity of the extension
of the period by the order dated 2.6.1985 made by the CEO in exercise of the
power under section 183-A Section 183 prescribes the period of one year from
the date on which a building sanction has been given to begin the building so
sanctioned, failing which the sanction lapses unless the Board, on an
application made therefor has allowed an extension of that period. In the
present case, the compliance of this provision is not disputed since the claim
of respondent no. 1 by a letter dated 3.7.1982 is not contested. the
significant provision is Section 183-A.
Section
183-A requires the period for completion of the building to be specified when
the sanction is granted. It is to be a resonable period after the work has
commenced. In the present case the period so specified was one year. The
fixation of the period of one year as the reasonable period for completion of
the building after commencement of the work was not challenged. Thus, the work
having commenced on 3.7.1982 as claimed by the respondent no.1, the period for
its completion according to Section 183-A, expired on 3.7.1983. Section 183-A
further provides that if the erection of the building is not completed within
the period so fixed, it shall not be continued thereafter without fresh
sanction obtained in the manner herein-before provided i.e.Section 181, unless
the Board on an application made therefor has allowed an extension of that
period. The proviso then limits the power of the Board to allow not more than
two such extensions.
In
short, Section 183-A provides for the specification of the period for
completion of the building when the sanction is granted and on expiry of that
period construction of the building cannot be continued without a fresh
sanction, unless an extension of that period has been allowed on an application
made therefor. It means that unless the Board has allowed an extension of the
period specified for complotion of the building on an application made therefor,
the sanction lapses and the construction of the building shall not be continued
thereafter without a fresh sanction. Section 183-A speaks of a fresh sanction
on expiry of the period fixed for completion of the building as well as
extension of that period on an application made therefor. Meaning must,
therefore, be given to both the provisions, namely, fresh sanction and
extension of that period; and the two powers must be construed to be available
in two different situations. This is necessary to exclude any conflict and
arbitrariness in exercise of the choice between the two powers in similar
cases. It appears that the two powers are meant to be exercised in two
different situations and the provision does not leave it to the option of the
authority to deside which of the two powers is to be exercised in the case.
This means that unless time is extended on an application made before its
expiry, the sanction lapses and the erection of the building cannot be
continued thereafter without a fresh sanction.
Effect
of the proviso in Section 183-A must also be kept in mind. Extension of time
allowed has to be in continuity and it cannot exceed the period fixed initially
for completion of the building. The limit is of two extensions. In the present
case, the period fixed was one year and, therefore, the permissible two
extensions could not exceed two years because of the proviso. Thus, the total
extension of time could not be beyond two year from 3.7.1983 (upto which date
time was allowed for completion). In other words, time extended under Sec.183-A
because of the proviso, in the present case could not be beyond 3.7.1983 since
the extension had to be in continuity. In the pesent case that application made
much later on 9.9.1985 had to be rejected by the CEO for this reason alone and
the only power available on that date was of a fresh sanction. This obviously
could not be granted in view of the additional restrictions imposed meanwhile.
Thus, extension of time by the order dated 2.5.1986 was clearly without
jurisdiction for this reason alone.
Even
assuming the power to allow extension of time was available, the facts indicate
that it could not be granted.
As
earlier stated, the period fixed for completion of the building under Section
183-A was one year which expired on 3.7.1983. Admittedly, no application for
extension of time was made by the respondent no.1 before the expiry of that
period and such an application is alleged to have been made only on 24.9.1983.
No extension was granted on that application since the Board does not admit
receiving the same. There was total silence till almost two years thereafter
and then on 9.9.1985 the application for extension of time was made by
respondent no. 1. The period fixed for completion of the building when the
sanction was granted had expired more than two years earlier. The report of the
officer of the Cantonment Board dated 3.10.1985 clearly showed that the
construction of the building had not commenced till then and the only thing
done was some excavation work. In spite of this report, the CEO granted
extension of time for completion of work for a further period of one year
without assigning any reason a in his order dated 2.5.1986 made with reference
only to the application dated 9.9.1985.
It is
obvious that the exercise of the statutory power of grant of extension of time
under Section 183-A is not mechanical or automatic and required a decision for
be taken on application of mind with reference to the relevant facts and
circumstances of the case. The CEO should have considered all the relevant
facts and circumstances of the present case. The CEO should have considered all
the relevant facts and circumstances of the present case before he came to the
conclusion that extension of that period was called for particularly, when no
construction of the building had been commenced till then and additional
restrictions had been imposed meanwhile according to which such a building
sanction could not be granted if the matter were to be considered for grant of
a fresh sanction contemplated under Section 183-A. Shri Nariman rightly does
not dispute that even if the additional restrictions were to apply
prospectively to the grant of a fresh sanction thereafter, this was a relevant
circumstance to be considered while deciding to grant extension of that period
even in this case. The total non-consideration of any relevant fact by the CEO
while granting extension of time by order dated 2.5.1986 and the absence of any
reason for grant of the sanction is alone sufficient to vitiate the CEO's order
dated 2.5.1986. This conclusion is reached even if it is assumed that extension
of time could be granted on an application made after expiry of the period
allowed for completion of the construction and the embargo in the proviso is
overlooked.
The
validity of the GOC-in-Chief's order setting aside the order of the CEO
granting extension of time has to be decided on the above conclusion reached by
us. The GOC-in- Chief's order refers, inter alia, to the additional
restrictions imposed in the meantime as relevant factors for consideration. It
is rightly not disputed that this was a relevant, factor to consider while
deciding the question of extending the period. In substance. the GOC-in-Chief
took the view that permitting the construction of such a building which had not
till then begun would flagrantly violate the building restrictions which had
come into force by then.
This
reason cannot be said to be arbitrary since it relates to a relevant fact for the
grant of extension of time. A perusal of the application dated 9.9.1985 made
the respondent no.1 indicates that no fact had been stated therein to make out
any ground for grant extension of time and to explain the inability to even
commence erection of the building within the time allowed. Even a reference to
the earlier application dated 24.9.1983, assuming it was filed, shows that
nothing significant was mentioned therein except some vague, general
difficulties of which the respondent no.1 must have been aware even while
seeking the initial sanction. Thus neither any facts or cogent grounds for
extension of time were mentioned in the application for extension of time nor
was any reason given by the CEO while granting extension of time by order dated
2.5.1986. This is sufficient to indicate that the grant of extension of time by
the CEO was an arbitrary exercise of tower under Section 183-A, even if the
power was available. The GOC-in-Chief was, therefore, right in setting aside
that order in exercise of his power under Section 52 of the Act.
In the
above view, the High Court was not justified in interfering with the orders
made by the GOC-in-Chief in exercise of his power under Section 52 of the Act.
Exercise of the power under Article 226 of the Constitution by the High Court
in favour of the respondents in such a case was, therefore, clearly
unwarranted. The High Court's order has, therefore, to be set aside.
Consequently,
the appeal is allowed; the impugned judgment of the High Court is set aside.
However, in view of the offer made on behalf of the appellants to permit
retention of the existing structure in the manner indicated above and to permit
finishing of the existing structure in the manner stated, we permit retention
of the same. The orders of the GOC-in-Chief would therefore, stand modified to
this extent only. The respondents to pay Rs.5,000/- as costs to the appellants.
Back
Pages: 1 2